1. The present Appeal No. 340 of 2016 has been preferred by M/s. Azure Sunrise Private Limited (Appellant) against the Impugned Order Dated 14th December, 2016 passed by the Karnataka Electricity Regulatory Commission (hereinafter the "State Commission") in Petition No. 19/ 2016 (hereinafter the "Petition"), wherein the State Commission has arbitrarily and unjustifiably retrospectively reduced the approved extension of time of 137 days granted by the distribution licensee, Chamundeshwari Electricity Supply Corporation Limited (hereinafter the "CESCOM") to only 25 days, after more than 12 months of such extension being granted and acted upon by both the parties and has further recorded that the necessary consequences as per the terms of the PPA (as defined hereinafter) shall follow.

1. The Appellant Company was established to execute what is known as Chennai Metro Rail Project ("CMRP"). On 15.02.2011, a Memorandum of Understanding ("MoU") was entered into between the Government of India, Government of Tamil Nadu and Chennai Metro Rail Limited ("CMRL"), the Appellant herein, inter-alia, for the purposes of sharing the financial burden of setting up of CMRP, the objective whereof concededly was to provide reliable, faster, economical and eco- friendly public transport services in the city of Chennai, the project undertaken being similar to the projects that have come up in different metro-cities of India including Delhi and Bangalore.

1. The present appeal has been filed by Indian Captive Power Producers Association (ICPPA) (Appellant) against the daily order dated 01.02.2019 ("impugned order") passed by the Gujarat Electricity Regulatory Commission ("Respondent Commission") in Petition No. 1672 of 2017, preferred by the Appellant. Vide the present appeal, the Appellant is seeking necessary directions for expediting the proceedings in Petition No. 1672 of 2017 preferred by the Appellant. Under the aforesaid Petition, the Appellant is seeking amendment of the provisions of the Gujarat Electricity Regulatory Commission (Terms and Conditions of Intra-State Open Access) Regulations, 2011 ("GERC OA Regulations, 2011") as detailed therein. However, even after a lapse of more than 2 years, the Respondent Commission has failed to hear the Petition on merits, thereby leading to a delay in deciding the said case.

1. The present Appeal has been filed by the Swasti Power Limited ("Appellant") under Section 111 of the Electricity Act, 2003 ("Electricity Act"), challenging the legality, validity and propriety of the Uttarakhand Electricity Regulatory Commission's ("State Commission / Respondent No.1") Order dated 21.10.2015 in Petition No. 08 of 2015 ("Impugned Order") whereby the State Commission despite coming to the conclusion that the Respondents are in breach of their obligations towards construction of 220/33KV sub-station at Ghansali or in strengthening/augmentation of the existing 33KV evacuation system had erroneously dismissed the Petition filed by the Appellant while holding that there is no specific condition under the Power Wheeling Agreement dated 30.09.2005 and Power Purchase Agreement dated 03.07.2009 executed between the parties, under which the Appellant could be compensated for the loss of generation due to inactions of the Respondent No. 2 & 3.

2. The facts, which led to filing of this appeal, in brief, are as under:

Admittedly, the 2nd Respondent is the HT consumer of electricity having Contract Demand of 3500 KVA with the Appellant. It entered into an agreement on 10.10.2011 with the Appellant-Discom for supply of power in terms of above Contract of Demand.

3. Apparently, consumer company made an application for energy drawl from open access through IEX and it was considered as short term open access (STOA) consumer. Admittedly, in terms of Regulation 26(vii) of the RERC (Terms and conditions for Open access) Regulations 2016 (for short "Regulations of 2016"), every short term open access consumer shall provide the injection/drawl schedule (block- wise maximum power) for inter-State transactions every day to SLDC, RDPPC and the Distribution Licensee before 10:00 am of the day 3 preceding the day of drawl/injection as per the open access capacity sanctioned.

1. By this appeal, challenge has been brought to order dated 04.03.2015 of first Respondent i.e. West Bengal Electricity Regulatory Commission (hereinafter variously referred to as "WBERC" or "State Commission") in case No. TP-55/13-14 thereby determining Multi Year Tariff (MYT) for the period beginning with financial year (FY) 2014-15 upto FY 2016-17 by which the appellant, representing a set of industrial consumers, claims to be adversely affected. The grievances of the Appellant relate to alleged inherent inconsistency in the approach on account of "excessive allowance of power purchase cost"; non-compliance of Tariff Regulations in matter relating to "Provisional Determination of Project Cost" of specific units; incorrect treatment of "non-tariff income"; and, erroneous "recurring" allowance of "interest on working capital loan" provided by Government of West Bengal without scrutiny as to delay in repayment.

Mr. Amit Kapur Ms. Poonam Verma Mr. Saunak Kumar Mr. Rajguru Mr. Sidhant Kaushik Ms. Aparajita Upadhyay Ms. Adhishree Chakraborty Ms. Sakshi Kapoor Counsel for the Respondent(s) : Ms. Abiha Zaidi for R-2 Order PER HON'BLE MR. S. D. DUBEY, TECHNICAL MEMBER IA No. 324 of 2020

1. The dismissal of the claim brought before the Haryana Electricity Regulatory Commission (the Commission) under Section 86(1)(f) of the Electricity Act, 2003 for recovery of Rs. 76,61,606/- on account of "deemed generation" against the Respondent Discom, registered as case No. HERC/PRO-69 of 2017 "for want of prosecution" by order dated 16.01.2019, followed by dismissal of the prayer for Appeal No. 75 of 2020 Page 2 of 6 restoration of the said case by order dated 25.04.2019, has led to the present appeal being instituted before us.

2. We have heard the learned counsel on all sides and have gone through the record. We are of the view that the appeal must be allowed. We set out our reasons hereinafter.

1. Against the backdrop of validity of certain acts of the third Respondent (Procurer) encashing the Performance Bank Guarantee and terminating the Power Purchase Agreement (PPA) being questioned by the Appellant (Developer), the issues of the propriety of the approach of Appeal No. 319 of 2019 & IA Nos. 1565, 1566 & 1915 of 2019 Page 2 of 37 the first Respondent - Uttar Pradesh Electricity Regulatory Commission (hereinafter referred to variously as "UPERC" or "State Commission" or "Commission") - to the process of adjudication and the general expectation of its neutrality particularly at the stage of an appellate scrutiny of its decision by this Tribunal have come up for consideration in this appeal.

1. The brief facts that led to filing of the present appeal are as under:

3

In terms of guidelines issued by Ministry of Power (MoP) for determination of tariff by bidding process for procurement of power by distribution licensees, on 18.05.2009, Respondent No.3- MSEDCL issued a request for proposal for procurement of 2000 MW (+30%-20%) for a period of 25 years on long term basis. In that process, the following bidders were qualified:

i. Emco Energy Ltd. ( 200 MW @2.879 Rs/kWh) ii. Rattan India Power Ltd. (Amravati) ( 1200 MW @ 3.260 Rs/kWh) iii. Adani Power Maharashtra Ltd (1200 MW @ 3.280 Rs/kWh) iv. Rattan India Power Ltd. (Nashik) (950 MW @ 3.450 Rs/kWh v. Wardha Power Company Ltd. (675 MW @ 3.620 Rs/kWh)

1. These two matters have come up against almost identical backdrop of proceedings recorded by Tamil Nadu Electricity Regulatory Commission (hereinafter referred to variously as "TNERC" or "State Commission" or "Commission"), the Appellant in first captioned appeal being Madurai Power Corporation Private Limited, which was the petitioner in D.R.P. No. 19 of 2012, the second captioned appeal having been instituted by Samalpatti Power Company Private Limited, petitioner in D.R.P. No. 16 of 2012.

2. It appears that the said two petitions had come up for consideration before the State Commission around the same point of time, the hearing having been concluded, the orders having been reserved by similar proceedings recorded on 21.12.2018. Noticeably at that stage, the State Commission was functional in full strength with the Chairman and two Members in position. Before orders could be passed in either of the said matters, one of the members (Mr. G. Rajagopal) Appeal No. 127 of 2019 and Appeal No. 146 of 2019 Page 3 of 8 demitted office in January, 2019. Meanwhile, certain written submissions had been placed on record by the parties which were respondents before the State Commission (respondents in these appeals as well). Along with the said written submissions, certain documents were submitted to which exception was taken by the appellants primarily on the ground that it was new material, taking on board the same amounting to (as per their contention) amendment of the pleadings, it being statedly impermissible at the stage at which it had been tendered for record. Since the Registry of the Commission seems to have returned such material upon objections being taken, the respondents herein were constrained to file applications - i.e. IA No. 1 of 2019 in the first captioned matter and IA No. 2 of 2019 in the other matter.

1. This Appeal is filed by Southern Power Distribution Company of Andhra Pradesh Limited challenging the impugned order dated 03.11.2017 passed by Andhra Pradesh Electricity Regulatory Commission (hereinafter referred to as "APERC/Commission").

2. The brief facts which led to filing of the present Appeal are as under:

(i) 2nd Respondent - M/s SNJ Sugars & Allied Products Pvt. Ltd.

is a sugar plant with co-generation power plant having capacity of 20 MW. It uses bagasse as a fuel for power generation. It approached the Non-conventional Energy Development Corporation of Andhra Pradesh Limited (known as "NEDCAP") for setting up of power plant and accordingly it got the approval on 07.04.2000.

1. The Appellant West Bengal State Electricity Distribution Company (WBSEDCL) has come up with the present appeal challenging the order dated 01.11.2019 of Central Electricity Regulatory Commission (the Central Commission) in Petition No. 298/MP/2018 which had been instituted by the Respondent Damodar Valley Corporation (DVC) seeking declaration as to right to recover a sum aggregating Rs.111,74,47,434 Crores towards principal and delayed payment surcharge at the rate of 1.5% per month as on 31.08.2019 along with further interest till payment. It appears that the Appellant had resisted the claim by raising the issue of limitation pleading that the Appeal No. 20 of 2020 Page 2 of 5 petition of DVC could not be entertained, it being time barred.

In 2013, the Royal Bank of Scotland said we had to reduce our Virgin One mortgage immediately by nearly £7,000. To do this, we sold shares and borrowed money.

It is a painful business being a hip replacement company in a pandemic, and Smith & Nephew, like the patients who are waiting for its products, has had little choice but to suffer in silence.

Midas tipped Mpac in July last year, when the shares stood at £2.03. It's been a bumpy ride since then, but the shares are already far above that level at £2.55.

The trust announced the payment of a 2.475p dividend per share for the second quarter of this year - 2.1 per cent higher than 12 months ago, and replicating the payment made three months earlier.

Willie Walsh, the chief executive of BA's parent IAG faces a grilling before the Transport Select Committee for cutting up to 12,000 BA jobs - more than a quarter of its workforce.

Analysts are predicting that Hammerson, which owns the Bullring in Birmingham, will be forced to raise money in a rights issue after a major deal to offload retail parks fell through.

From this Wednesday, small business owners can apply for £3,000 of free advertising in DMGT's stable of newspapers.

The Wrinkle In Time director recounted how Little Richard helped her out during her college days with generous tips while she waitressed. She'd go on to become an acclaimed filmmaker.

Even though summer plans are being hampered due to the coronavirus pandemic, this model is still banking on the hopes that consumers will snatch up the gorgeous swimsuit looks she's selling.

The TV and radio host, 49, beamed as she donned a red floral maxi dress and sandals to take her seat in the family campervan.

The 30-year-old Pretty Little Liars alum rocked skinny jeans and a pair of black ankle boots for the solo outing.

Martha Kalifatidis is hoping to bring old Hollywood glamour back.

The comedian, 47, real name Leigh Francis, has revealed how upset he was over his co-presenter's departure after 12 years.

Marissa Rancan is the latest confirmed housemate for the Big Brother reboot. 

The Oasis star, now 52, did not expose the identity of the mystery guest but admitted it was very bizarre behaviour.

Zooey Deschanel and boyfriend Jonathan Scott will be celebrating moms by hosting a Mother's Day version of game night with their fans on Sunday, May 11.

Australian celebrities are marking Mother's Day in very different ways this year, as coronavirus restrictions keeps many families apart. 

Sally-Anne Huang, 47, will take the reins as the next high master of the west London private school which boasts a ream of notable alumni including former Prime Minister Spencer Compton.

Almost 4,000 members of the Armed Forces pension scheme breached their annual allowance in 2017-18. This puts them at risk of five or six-figure tax bills under changes introduced in 2016.

Receipts from residential purchases fell 10 per cent in 2018/19 to £8.4billion compared with the previous year. This is the biggest fall since house prices collapsed during credit crunch in 2008.

If the Royals were still being paid by the long-established Civil List, they would not benefit from the energy auction. But in 2012 this changed and the Queen now gets 25 per cent of the estate's profit.

The 29-year-old moved to the Wanda Metropolitano last summer having fallen out of favour in north London, with the La Liga side splashing £20million on the England international.

The vote was held on Ligue 1's official Twitter account, with Drogba receiving 51 per cent of the 40,094 votes that were cast.

United dithered over whether to pursue a deal for the Canadian youngster, who was playing for Vancouver Whitecaps at the time, with the youngster eventually signing for the Germans.

The night ended with some of the team playing Connect 4 in a remote hotel and others heading for the bright lights in a clapped-out Spanish saloon car.

Fresh evidence that Russian footballers were helped to cheat during their nation's state-sponsored doping scandal will arrive at FIFA within weeks.

EXCLUSIVE BY OLIVER HOLT AND ROB DRAPER: The dissident Premier League clubs arguing against a quick return to football will urge a delay to Project Restart.

The Football League will announce next week that there will be no further games in Leagues One and Two - but that the play-offs could still take place to determine who wins promotion.

Both Barcelona and Real Madrid are planning to slash their first-team wages by 30 per cent ahead of the 2020-21 La Liga season, according to Spanish newspaper Diario AS. 

The centre-back has produced some impressive performances for the Championship side and was recommended to United by club legend Ryan Giggs, who has coached Rodon for Wales.

The 24-year-old has been one of the standout players in the Premier League this season despite playing in a struggling Villa side who sit 19th, leading to interest from Manchester United.

Manchester City's lawyers are raring to go when it comes to appealing the club's two-year Champions League ban, according to The Mirror. The club also received a £25million fine for FPP breaches.

KIERAN GILL AT SELHURST PARK: Jordan Ayew scored a brilliant first-half strike to earn Crystal Palace a 1-0 victory over Watford to remind the Hornets of the relegation worries.

MARTIN SAMUEL AT OLD TRAFFORD: Ignore for a moment the fact that for many Mancunians this win may bring forward a date with dreaded destiny, when Liverpool win their first Premier League

An enthralling weekend of Premier League football saw Manchester United and Chelsea push clear in the fight for a top four place while Liverpool moved to within two wins of the title.

The Eagles have also called season-ticket holders and offered to help them with their shopping. @LiamWalker_7 on Twitter described how a member of staff from the London club contacted his dad.

Wilfried Zaha says it is nice to see former Crystal Palace team-mate Aaron Wan-Bissaka getting recognised on the world stage since his move to Manchester United.